Receive a free renovation tracker with any purchase!
Terms & Conditions
Welcome to The Render Co. By accessing or using our website and services, you agree to comply with and be bound by the following terms and conditions. Please read them carefully before engaging with our services.
1. Acceptance of Terms
By using this website, you agree to these Terms and Conditions and our Privacy Policy. If you do not agree, you must not use our website or services. Continued use of our website constitutes your acceptance of any updates or changes to these terms.
2. Intellectual Property
All content on this website, including text, graphics, logos, images, and software, is the property of The Render Co. or its content suppliers and is protected by copyright, trademark, and other intellectual property laws. Unauthorized use, reproduction, or distribution of any materials is prohibited and may result in legal action.
3. Use of Services
- Our design packages are intended for personal, non-commercial use only. Redistribution, reselling, or reproducing our deliverables without explicit permission is strictly prohibited.
- You agree to provide accurate, complete, and current information when requested, including for project details and purchasing.
- The Render Co. provides design deliverables, including layouts and renderings, as general design guidance. We do not coordinate with third-party contractors or oversee construction projects.
- All measurements provided in our designs are approximate and not intended for construction purposes. Professional verification on-site is required prior to implementation.
- The Render Co. reserves the right to decline services or terminate access to our website for violations of these terms.
4. Collection and Use of Personal Information
- To purchase our packages, we may collect personal information, including your name, email address, and payment details.
- Your information will only be used for processing transactions, delivering services, and improving customer experience.
- By providing your email address, you consent to receiving communications from us related to your purchase and promotional offers. You can unsubscribe from marketing emails at any time.
- We do not sell, rent, or share your personal information with third parties, except as required to fulfill our services or comply with legal obligations. For more details, refer to our [Privacy Policy].
5. Pricing and Payment
- Prices for our design packages are listed on the website and are subject to change without notice.
- Payment must be made in full at the time of purchase through our secure payment gateway. We accept major credit cards and other approved payment methods.
- Due to the personalized nature of our services, refunds are not available once the design process has begun, defined as the completion of the design questionnaire. Cancellations made within 24 hours of purchase are eligible for a full refund.
6. Scope of Deliverables
- The deliverables for each package are explicitly outlined in the package descriptions. Any additional work or revisions beyond the agreed scope may incur extra fees.
- Deliverables are provided in digital format unless otherwise specified. Physical copies, if required, will be subject to additional charges.
- Our designs are conceptual and meant for visualization purposes. They are not intended to replace detailed architectural or engineering plans.
- All designs and layouts must be reviewed and approved by licensed professionals before any construction begins.
7. Limitation of Liability
The Render Co. is not liable for:
- Construction errors or issues resulting from the implementation of our designs by third parties, including contractors hired independently by the client.
- Measurements provided in our designs, which are approximate and not intended for construction use. All final measurements must be verified by a licensed professional on-site before any construction begins.
- The interpretation or application of our 3D renderings, which are for illustration purposes only. These renderings are conceptual and not intended as a substitute for professional architectural or engineering plans.
- Variations in colors, finishes, or materials due to screen display differences or supplier changes.
- Delays caused by third-party vendors, contractors, or suppliers.
- Errors or inaccuracies in measurements provided by clients.
- Any indirect, incidental, or consequential damages arising from the use of our website or services.
8. Indemnification
You agree to indemnify, defend, and hold harmless The Render Co., its affiliates, and employees from any claims, liabilities, damages, and expenses (including legal fees) arising out of your use of our website or services, violation of these terms, or infringement of any third-party rights.
9. Disclaimer of Warranty
The Render Co. provides services and deliverables on an "as is" basis without warranties of any kind, either express or implied, including but not limited to implied warranties of merchantability, fitness for a particular purpose, or non-infringement.
10. Force Majeure
The Render Co. shall not be held liable for any failure or delay in performance due to causes beyond its reasonable control, including but not limited to acts of God, labor disputes, natural disasters, or interruptions in internet or telecommunications services.
11. Errors, Inaccuracies, and Omissions
Occasionally, there may be information on our site or within our services that contains typographical errors, inaccuracies, or omissions relating to product descriptions, pricing, promotions, offers, or availability. The Render Co. reserves the right to correct any errors, inaccuracies, or omissions and to change or update information or cancel orders if any information on the website or related services is inaccurate at any time without prior notice (including after you have submitted your order).
We undertake no obligation to update, amend, or clarify information on the website or within our services, including pricing, except as required by law. No specified update or refresh date should be taken to indicate that all information has been modified or updated.
12. Digital Products and Educational Materials
- Any e-books, budgeting spreadsheets, or other digital materials provided by The Render Co. are for informational and educational purposes only.
- While we strive to ensure the accuracy and reliability of our materials, we do not guarantee that they will meet your specific needs or expectations.
- Budgeting tools and spreadsheets are general templates and do not constitute financial, legal, or professional advice. Consult with a qualified professional before making financial decisions based on these materials.
- The Render Co. shall not be held liable for errors, omissions, or inaccuracies in the materials or any decisions made based on their use.
13. International Use
- Our services, digital products, and packages are offered globally, but The Render Co. does not guarantee that materials and designs comply with local regulations, building codes, or standards in your country or region.
- It is the client’s responsibility to ensure compliance with applicable laws and regulations in their jurisdiction.
- Any disputes or claims will be governed exclusively by the laws of [Your State/Region], regardless of the client’s location.
- Clients are responsible for verifying the compatibility of our services with local legal requirements, including export control laws where applicable.
14. Limitation on Professional Advice
- The Render Co. is not an architectural, engineering, or financial advisory firm. Services and materials provided are intended to inspire and guide, but they do not replace professional advice.
- Always consult with licensed professionals, including architects, contractors, engineers, and financial advisors, for your specific project requirements and local regulations.
15. Digital Accessibility
- We strive to ensure that our website and digital content are accessible to all users. However, we are not liable for any issues arising from accessibility limitations.
- If you encounter accessibility issues, please contact us so we can work to address them promptly.
16. Non-Transferability
- The rights and licenses provided under these Terms and Conditions are non-transferable. Any attempt to assign or transfer without written consent from The Render Co. will be void.
17. Dispute Resolution
Any disputes arising out of or relating to these Terms and Conditions or your use of our services shall first be attempted to be resolved through mediation. If mediation fails, the dispute shall be resolved through binding arbitration in accordance with the rules of [Your Region's Arbitration Association].
18. Governing Law
These Terms and Conditions are governed by the laws of [Your State/Region]. Any disputes or claims will be resolved exclusively in the courts of [Your State/Region].
19. Third-Party Vendors and Links
Our website may contain links to third-party websites or services. The Render Co. is not responsible for the content, terms, privacy policies, or practices of these third parties. Use of such third-party services is at your own risk.
20. Updates to Terms
We reserve the right to update or modify these Terms and Conditions at any time without prior notice. It is your responsibility to review these terms periodically. Continued use of the website after any changes indicates your acceptance of the updated terms.
21. Limitation on Liability for Third-Party Integrations
The Render Co. may integrate or link with third-party platforms for payment processing, file storage, or other services. We are not responsible for the availability, functionality, or data security of these third-party services. Use of such services is at your own risk.
22. Entire Agreement Clause
These Terms and Conditions, along with our Privacy Policy, constitute the entire agreement between you and The Render Co. concerning the use of our website and services. They supersede any prior agreements, communications, or understandings.
23. Termination Clause
We reserve the right to terminate your access to our website or services at our sole discretion, without notice, for violation of these Terms and Conditions, fraudulent activity, or other behavior deemed inappropriate or harmful.
24. Intellectual Property Indemnity
You agree to indemnify and hold harmless The Render Co. from claims alleging that any of our designs or materials infringe on third-party intellectual property rights, except when the infringement arises directly from content provided by us.
25. User-Generated Content
If applicable, you retain ownership of any content you submit to our platform but grant The Render Co. a non-exclusive, royalty-free license to use, modify, and distribute your content as needed for service delivery. We are not responsible for any unlawful or infringing content uploaded by users.
26. No Guarantee of Results
The Render Co. does not guarantee any specific results, such as construction success or financial savings, from using our designs, materials, or digital products. Outcomes depend on external factors beyond our control.
27. No Waiver Clause
Failure to enforce any provision of these Terms and Conditions shall not constitute a waiver of that provision or any other provision.
28. Contact Information
If you have any questions about these Terms and Conditions or require further information, please contact us:
Email: info@therenderco.com
29. Privacy and Security
The security of your personal information is important to us. We use industry-standard encryption and secure payment gateways to protect your data. For more details, please refer to our [Privacy Policy].
30. Service Availability Disclaimer
The Render Co. does not guarantee uninterrupted access to its website or services. Downtime for maintenance, updates, or technical issues may occur. We are not liable for any losses resulting from such interruptions.
31. Prohibited Uses
You agree not to use our website or services for any unlawful or unauthorized purposes, including but not limited to hacking, data mining, distributing malware, or violating intellectual property rights.
32. Cookies and Tracking Technologies
The Render Co. uses cookies and similar tracking technologies to enhance user experience and analyze website traffic. By using our website, you consent to our use of cookies. For more information, refer to our Cookie Policy.